Padel Court Options - Built for Every Enviroment

PadelGo offers three world-class court types, each designed for differant enviroments and performance needs. Whether you're building a court for a school, sports club, resort or private use our options guarentee top quality play, durability and safety. Descover which PadelGo court is right for your project below.

Our Courts!
We offer three premium Padel Tennis court options:
Panoramic Court (20m x 10m) – Reliable and fully equipped, with a 2-year warranty on the court structure, glass, mesh, and turf.

 Super Panoramic Court (20m x 10m) – Built for extra durability, with a 2-year warranty covering turf & 5 year warranty on the structure, glass and mesh.

Coastal Guard Panoramic Court (20m x 10m) – Our flagship design, engineered in South Africa to withstand the harshest coastal and inland conditions. Features unique pillars and a reinforced foundation with a 5-year structural guarantee, plus a 2-year warranty on the glass, iron mesh, and turf.

Padelgo Montana Dome (20m x 10m) - Panoramic Padel Tennis court with a roof, includes lights, structural guarantee. Contact us for quotation.

Experience world-class Padel Tennis courts designed to last and perform in any environment.

Terms & Conditions of Sale

1. General
1.1. These Terms and Conditions of Sale (“Terms”) apply to all sales of
Padel Tennis Courts (“the Product”) by Innard (Pty) Ltd (“Padelgo”) to
any client (“the Buyer”).
1.2. By accepting a quotation, making payment, or signing a sales
agreement, the Buyer acknowledges that they have read, understood,
and accepted these Terms in full.
1.3. The Buyer must read the section titled “What You Need to Know”
on the Padelgo website (www.padelgo.co.za) before proceeding with any
purchase. This document forms an essential part of the sale and provides
important information about the process, requirements, and expectations
related to the project.
2. Legal Representation
2.1. All contractual and legal queries regarding project terms will be
managed exclusively by Padelgo’s appointed legal representative,
Mr. Chris O’Neil, who will act on behalf of Innard (PTY) Ltd in all formal
communications and contractual matters.
3. Sales Agreement and Payment Schedule
3.1. The final Sales Agreement will include a Payment Schedule,
which shall form part of and be attached to the official Invoice.
3.2. Upon written acceptance of the quotation and payment of the agreed
deposit, the Buyer authorises Innard (PTY) Ltd to use the deposit to
secure all necessary services, materials, transport, bookings, and
logistics required to meet the agreed project timelines.
3.3. Innard (PTY) Ltd undertakes to use the deposit for project-related
expenses to ensure on-time delivery, including but not limited to
manufacturing, import arrangements, and booking of installation teams.
4. Project Delivery and Buyer Responsibilities
4.1. The Buyer is responsible for ensuring that the site and foundation
are completed, inspected, and ready for installation on the agreed start
date.
4.2. Any delay caused by incomplete or non-compliant site preparation
may result in additional costs to the Buyer, including but not limited to:
• Storage fees for equipment and materials;
• Security costs for safeguarding goods;
• Additional transport and handling charges;
• Accommodation deposits or extended staff housing costs;
• Interest charges where the full payment is not made in accordance
with the payment schedule; and
• Any other documented costs arising directly from the delay.
5. Changes and Amendments
5.1. All changes, variations, or amendments to the Sales Agreement or
project scope must be submitted in writing by the Buyer.
5.2. Innard (PTY) Ltd will have seven (7) business days to respond in
writing, outlining the impact of the requested change and suggesting
possible remedies or adjustments depending on the stage of the project.
5.3. Any approved changes will only become effective once agreed to in
writing by both parties.
6. Payment Terms
6.1. Payments must be made strictly according to the agreed Payment
Schedule outlined in the Sales Agreement.
6.2. Late or incomplete payments may cause project delays and result in
interest charges and other associated costs.
6.3. Ownership of the court and all materials remains with Innard (PTY)
Ltd until full payment has been received.
7. Resale or Transfer of Ownership
7.1. Should the Buyer wish to resell or transfer ownership of the
court, the Buyer must submit a written instruction to Innard (PTY) Ltd
prior to the transaction.
7.2. All standard Terms & Conditions will remain applicable, and any
additional administrative or transfer-related costs will be charged to the
Buyer.
8. Liability and Delays
8.1. Innard (PTY) Ltd will take all reasonable steps to ensure timely
delivery and installation; however, Innard (PTY) Ltd shall not be liable for
delays caused by circumstances beyond its control, including but not
limited to customs delays, transport disruptions, weather conditions, or
site readiness issues.
8.2. In such cases, new delivery dates will be mutually agreed upon in
writing.
9. Governing Law and Jurisdiction
9.1. These Terms are governed by and construed in accordance with the
laws of the Republic of South Africa.
9.2. Any dispute arising from or related to these Terms shall be handled
in accordance with South African legal procedures, with Padelgo’s
appointed attorney, Chris O’Neil, as the primary point of contact for
mediation or legal representation.
10. Acceptance
By accepting a quotation, signing the Sales Agreement, or paying the
deposit, the Buyer acknowledges and agrees to all terms and conditions
contained herein and confirms that they have read and understood all
information provided by Innard (PTY) Ltd & Padelgo Marketing, including
the “What You Need to Know” section on the company website.